By using the services provided by Zip-Estimate, you agree to the following terms and conditions:
- Service Description: Zip-Estimate provides a platform for homeowners to connect with certified contractors for remodeling projects. This includes obtaining estimates and accessing incentives where applicable.
- Contractor Selection: Users can book up to 3 contractors through Zip-Estimate to obtain estimates for their remodeling projects. The selection of contractors is based on availability and geographic proximity to the user’s location.
- Estimates and Pricing: Estimates provided by contractors through Zip-Estimate are for informational purposes only and may vary based on the specifics of the project. Users are encouraged to discuss pricing details directly with the selected contractors.
- User Responsibilities: Users are responsible for providing accurate information about their remodeling project and ensuring that their Zipcode and project type qualify for any available incentives.
- Certified Contractors: Zip-Estimate works with certified contractors who have been vetted for quality and reliability. However, users are encouraged to conduct their own due diligence before entering into any agreements with contractors.
- Liability: Zip-Estimate is not liable for any damages, losses, or disputes arising from interactions between users and contractors, including but not limited to project delays or unsatisfactory workmanship.
- Privacy Policy: By using Zip-Estimate, you agree to our Privacy Policy, which governs the collection, use, and disclosure of personal information provided by users.
- Contact Information: By applying on our forms, you agree to allow Zip-Estimate to send your contact information to certified contractors and to contact you via text or call for project updates.
- Governing Law: These terms and conditions are governed by the laws of the State of Texas, and any disputes arising from or related to these terms shall be resolved in the courts of the State of Texas.
By using Zip-Estimate, you acknowledge that you have read, understood, and agree to abide by these terms and conditions. If you do not agree with any part of these terms, please refrain from using the Zip-Estimate platform.
